There is a clause in the FIDIC contract on how to understand the contractor s compensation after the

It is normal to delete a piece of work. In the case of design changes, both the owner and the engineer can do so. The compensation to the contractor shall be the related expenses incurred by the contractor for the ancillary work completed or the equipment invested in order to complete the work, and the contractor shall not be able to claim profit for the direct loss part.

When this derogation exceeds the contract**25%, there is a **adjustment or it is processed in accordance with the relevant contract terms.

The owner does not have the right to arbitrarily delete the work. The original work, together with other work, constitutes the entire contract.

1. The expected profit of the original job is one of the reasons for signing the contract. For reasons of the owner, the work was cut and it was necessary to compensate the contractor for the profits.

2. Some taxes are in the form of lump sums.

3. Some overheads will not be reduced due to the reduction of workload. Such as office space, management salaries, and so on.

To put it simply, the owner said that the contract was 50 million, signed the contract, and told the contractor that I deleted 30 million of them, and only 20 million remained. Isn't it fraud ...

Let's say I'm a taxi driver and a customer says he's coming at 5 a.m. tomorrow to go 300 kilometers away. As soon as I heard that there was a big order, I ran to pick up people with great interest the next morning, but as soon as the person got in the car, he said that he couldn't go, and only went to a place of 1 kilometer. You say it's not a waste of my feelings, is it appropriate to only give 1 km fare?

Answer]: b, c, d

The answer is as follows: according to Section 5 of Chapter 5 of the "Valuation of Construction Workers' Matching Schedule", items b, c, and d should be selected.

Analysis] The contractor may notify the engineer of its loss and provide specific supporting information, and the engineer and the contract parties shall negotiate to determine a compensation to be included in the contract price.

With regard to engineering changes under FIDIC contract conditions, the following questions have been included in the past exam questions since 2007:

2009 Exam Questions) Under the conditions of the FIDIC construction contract, the engineer issues a change order to delete a certain part of the work, and the contractor loses the loss of the loss benefit excluding ( ).

a.The direct cost of this part of the work.

b.This part of the work is shared in the overhead costs.

c.This part of the work shares the profits.

d.This part of the work is a share of taxes.

The correct answer is a.

Answer]: b, d, e

The claims for which the contractor can only be compensated for the duration of the construction under the conditions of the FIDIC construction contract include: 1) an extension of the completion time due to a change;

2) unusually unfavorable climate strips;

3) Delay in the construction period due to infectious diseases or other ** behaviors;

4) interference from the owner or other contractors; Grip sleepy.

5) Delays caused by public authorities. See Chapter VI, Section 2, p301. 【Key Points of Assessment】Positive Matching Construction Period Claim.

Answer]: Bifeng shoots A

Answer] A Regret Analysis] The basic question examines the main types of claims. Under a FIDIC construction contract, if the employer terminates the contract, the contractor is entitled to claim costs and profits.

Answer]: a, b

This question examines the engineer's review of the claim. The contractor may claim compensation for the following expenses: delay in the issuance of drawings; delay in handing over the construction site of Shi Xihuai Town; The contractor caused the pay-off error based on the erroneous data provided by the engineer; unforeseen external conditions; cultural relics and monuments encountered during construction; Delays in construction due to non-contractor inspections; The owner occupies the project in advance; interference with as-built inspections; Subsequent regulatory adjustments; The owner's insurance did not receive reimbursement from the insurance company; Damage caused by a force majeure event.

It clearly refers to the new textbook of this knowledge point has been deleted).

Answer]: After Engineer A issued a change order to reduce the work, the contractor no longer actually counted the part of the work, and there was no loss of the part of the direct costs included in the contract**, but the amortization of the indirect costs, profits and taxes in this part was not actually reasonable**. See textbook P271.

This question is aimed at the knowledge point of "settlement of international engineering contract price" for assessment] banquet demolition.

Answer] :d 2022 2021 edition textbook p183

This question examines the main types of claims. According to the FIDIC "Conditions for Construction", the contractor can claim compensation for the duration, expenses and profits when the change of construction occurs.

Correct Answer: a

Analysis: A [Analysis] The claim for extension of the construction period usually includes two aspects: first, the contractor requests an extension of the construction period; Second, the contractor demanded compensation for the losses caused by the delay of the project due to non-contracted reasons.

The delay caused by the 3rd bureau only claims the construction period, the owner should be insured but not insured only claims the cost, and the loss caused by force majeure is erected, and the contractor can claim the construction period and cost at the same time.